银行保函类型

贾彦婕 分享 时间: 收藏本文

【简介】感谢网友“贾彦婕”参与投稿,下面是小编整理的银行保函类型(共11篇),希望能帮助到大家!

篇1:银行保函类型

银行保函类型

对外保函主要有如下具体保函种类:

1、投标保函

主要用于国际投标与招标业务,通常是招标人要求投标人参加投标的条件之一。银行(担保人)应投标人(申请人)的申请,开立的以招标人为受益人的保函,保证投标人在开标之前不中途撤销投标、不片面修改投标条件或中标后不拒绝签约、不拒绝交纳履行保证金或提供银行的履约保函,否则银行将支付给招标人一定的金额作为赔偿。其目的在于表明投标人的诚意与资格。

2、履约保函

是银行(担保人)应交易合同中的一方当事人(申请人)的请求,开立的以另一方当事人为受益人的保函,承诺在申请人未能履行合同规定的义务时,银行将支付给受益人一定金额作为赔偿。

3、预付款保函

是指银行(担保人)应交易合同中的一方当事人(申请人)的请求,开立的以另一方当事人为受益人的保函,在申请人没有履行合同中规定的义务时,银行将保证偿还受益人预付或已付给申请人的金额。

4、质量与维修保函

是指应供货方或承建人申请,向买方或业主保证,如货物或工程的质量不符合合同约定而卖方或承建人又不能依约更换或修理时,按买方或业主的索赔予以赔偿。

5、留置金保函

是指部分进口贸易中,按合同规定对进口方尚未偿付的一小部分货款(即留置金),应出口方的要求,由进口方向银行申请开立的留置金偿付保证书。

6、借款保函

我行接受借款方的请求,向贷款方出具保函,如借款方不按期向贷款方偿还借款本息,我行将根据贷款方的索赔,按照保函约定承担付款责任。

7、融资租赁保函

在融资租赁活动中,我行接受承租方请求,向出租方出具保函,如承租方不按期支付租金,我行将根据出租方的索赔,按照保函约定承担付款责任。

8、补偿贸易保函

银行根据设备或技术引进方请求,以出具补偿贸易保函的`形式向设备或技术提供方提供第三方保证。补偿贸易保函的服务对象是补偿贸易项下的设备或技术使用企业,为其向设备或技术提供方承诺,当设备或技术引进方在设备或技术引进后的一定时期内没有将以其所生产的成品或其他产品来抵偿所引进的设备或技术的价值,或没有以成品的外销所得的款项支付所引进的设备或技术,而且届时无法或无力做出支付或抵偿行为时,银行将根据设备或技术提供方要求,按照约定承担保证责任。

篇2:银行保函范本

银行借款保函

致:受益人To: The beneficiary 保函编号 Our Ref. No.

出具日期 Date:

经——通知 ADVISED THROUGH_____

敬启者Dear Sirs,

我行第×××号不可撤消保函

Our Irrevocable Letter of Guarantee No.

根据贵方于×年×月×日与××(以下简称甲方)在×××地签署的第××号贷款协议,应甲方的要求,我们特此开立以贵方为受益人的第××号,金额不超过×××的不可撤消担保函。

With reference to the Loan Agreement No. _____ signed between your good selves and______ (hereinafter referred to as Party A) in place on date and at the request of Party A, we hereby establish in your favor an Irrevocable Letter of Guarantee No.______ for an amount not exceeding______ (in words).

我们保证,在贵方向甲方提供了协议所规定的贷款后,甲方将在协议规定的期限内偿还贵方上述贷款及其按年利率百分之×计算的利息。如果甲方未能在协议规定的时间内全部地或部分地偿还有关贷款的本息,我们保证在本保函有效期内收到本保函的通知银行转来的经甲方证实了的书面索赔通知后,将甲方未偿还之贷款本息偿还给贵方。

We guarantee that, after you provide Party A with the loan as stipulated in the Agreement, they will repay you the principal as well as the interest accrued thereon at______ % p.a. within the time in accordance. with the terms and conditions of the Agreement. Should Party A fail to repay you the loaned amount plus interest wholly or partially within the time limit, we undertake to effect the aforesaid repayment plus interest on their behalf, after we have received from the advising bank within the validity of this L/G your written demand to be verified by Party A.

本保函的担保金额将随甲方或我方已向贵方偿还的本息金额而同比例递减。

The ensured amount under this L/G will reduce in proportion to the amount(s) plus interest already repaid by Party A and/or by us.

本保函自甲方收到贵方的贷款之日起生效,于×年×月×日失效。到期后,请将本保函退还我行注销。

This L/G is valid from the date when Party A receives the said Loan from you until __ and should be returned to us for cancellation upon its expiry.

Guarantor:______

担保人(签字、盖章)

履约保函

PERFORMANCE BOND

致:受益人

To: The beneficiary 保函编号 Our Ref. No.

出具日期:Date:

敬启者Dear Sirs,

履约保函

PERFORMANCE BOND

本保函是为(申请人名称)(以下简称供货人)根据(合同编号及签署日期)向(受益人)提供(货物名称)而出具的。

This bond is hereby issued to serve as a performance bond of name of the applicant for the supply of name of goods for name of the sales contract and its number.

(担保人名称)特此不可撤消地保证自己、其继承人和受让人在下列情况下,无追索地用美元向你方支付合同金额的×%,即(担保金额):

The name of the guarantor hereby irrevocably guarantees and binds itself, its successors and assignees to pay you, without recourse, up to the total amount of currency and figures representing X percent (X%) of the contract price in US dollar and accordingly covenants and agrees as follows:

(1)如果供货人未能按合同及其后可能作出的合同变更、合同修改、合同补充和合同变动,包括对不合格商品的更换或修补条款履行责任(以下简称违约),则我们在收到你方指出供货人违约的书面通知时,向你方支付索赔书上所要求的一笔或数笔款项,但不超过本保函担保的总金额(担保金额)。

a) On the supplier's failure of the faithful performance of all the contract documents and modifications, amendments, additions and alterations thereof that may hereafter be made, including replacement and/or making good of defective goods (hereinafter called the failure of performance) as determined by you and notwithstanding any objection by the Supplier, the Bank shall, on your demand in a written notification stating the effect of the failure of performance by the Supplier, pay you such amount or amounts as required by you not exceeding in aggregate amount of guarantee in the manner specified in the said statement.

(2)本保函项下的付款将不减去任何现在的或将来的税款、费用扣留等。

b) Any payment hereunder shall be made free and clear of and without deduction for or on account of any present or future taxes, duties, charges, fees, deductions or withholding of any nature whatsoever imposed.

(3)本保函内所含的各项约定构成了担保银行不可撤消的直接责任。上述合同中的任何条款变更,你方所允许的时限或作出的任何行为或发生的疏漏,尽管可能免责或解脱银行,都不能解除银行的此项责任。

c) The covenants contained herein constitute irrevocable direct obligations of the Bank. No alteration in the terms of the contract to be performed there under and no allowance of time by you or any other act or omission by you which for this provision might exonerate or discharge the Bank shall in any way release the Bank from any liability hereunder.

(4)本保函自上述合同签署之日起生效直至(合同失效日)为止。本保函到期后,请将其退回我方注销。

d) This guarantee shall become effective from that date of the signing of the said contract and shall remain valid until the date of its expiry. Upon expiry, please return this guarantee to us for cancellation.

担保人:(签字、盖章)

Guarantor:______

预付货款保函

致:受益人To:The beneficiary 保函编号:Our Ref.No

出具日期:Date:

敬启者:Dear Sirs,

我行第××号预付货款保函

Our Advance Payment Guarantee No....

鉴于贵方根据与(申请人名称)(以下简称合同方)于×年×月×日签署的第××号合同的有关条款的规定,在收到合同方提供的有关预付货款保函后,将向合同方预付(预付金额)作为合同项下的预付款。

WHEREAS according t0 the terms and conditions of the sales contract No…signed between you and name of the Applicant (hereinafter referred to as the Contractor) ,you shall.on receipt from the Contractor of a bank guarantee for such advance payment to you· make an advance payment of—amount in figures and in words to the Contractor as an advance payment thereunder.

我们(担保人名称)应合同方的要求,特此开立本保函并向你方不可撤消地保证,在收到你方书面索赔通知声明合同方未能履行上述合同有关条款时,支付给你方不超过担保金额的款项。

NOW THEREFORE,we(name of guarantor)at the request of the Contractor hereby irrevocably issue this Advance Payment Guarantee and undertake to pay you, upon receipt of your written demand stating that the Contractor has failed to perform his obligations as stipulated in the Contract, the sum or sums not exceeding the above-mentioned amount.

我们在本保函项下的担保责任仅限于(保函金额)。

Our liability hereunder shall be limited to (the amount of guarantee).

本保函从合同方收到你方支付的上述预付款之日起生效,到(保函失效日)失效。 我们的担保责任将随合同方已经支付给你方的金额而自动同比递减。 保函到期后,请退回我们注销。

This guarantee shall become effective on the date the Contractor receives the aforesaid advance payment from you and shall remain valid until (the expiry date of this guarantee). The guaranteed amount shall be automatically and proportionally reduced by the amount which the Contractor has already repaid to you. Upon its expiry, please return this guarantee to us for cancellation.

担保人:(签字、盖章)

Guarantor: (signature, seal)

篇3:银行保函

(预付款保函)银行保函样本1

致: (下称受益人):

鉴于 (下称被担保人)已与受益人签订了合同编号为 ___________的 (下称合同),工期自 年 月 日至 年 月 日,且受益人向被担保人支付了金额为_ 的预付款。我方接受被担保人的委托,在此向受益人提供不可撤销的预付款保函:

一、 本保函的最高担保金额为 人民币 (币种) ¥ (小写) (大写)。

二、本保函的有效期自 年 月 日至 年 月 日。

三、在本保函的有效期内,我方将在收到受益人经法定代表人或其授权委托代理人签字确认并加盖公章的关于受益人认定被担保人违反合同约定的书面索赔通知及本保函原件后 15 个工作日内,不争辩、不挑剔、不可撤销地向受益人支付索赔款,但累计索赔金额不得超过本保函的最高担保金额。

四、索赔通知应当说明索赔理由、索赔款额的计算方法,并必须在本保函的有效期内送达我方,超过有效期的索赔将不会再得到我方的任何支付,保函到期后,无论受益人是否退回保函原件,我方的担保责任均自动解除。

五、本保函项下的权利不得转让。

六、我方提供本保函担保后,受益人与被担保人对合同进行修订的,应当将修订后的合同原件送我方备案。

七、本保函的有效期届满,或我方向受益人支付的索赔款已达本保函的最高担保金额,我方的担保责任免除。

八、本保函适用中华人民共和国法律。

九、本保函以中文文本为准,涂改无效。

担保人: (盖章)

负责人人或其授权委托代理人(签字或盖章):

单位地址:

邮政编码: 电话: 传真:

日期: 年 月 日

(履约保函)银行保函样本2

致:

鉴于_________________________________________(以下简称乙方)已保证按_____________________________(编号:_________________________)(以下称“合同”)实施;

且鉴于你方在上述合同中要求乙方通过经认可的银行向你方提交合同规定金额的不可撤销的银行保函,作为乙方履行合同责任的担保;

而且本行同意为乙方出具本银行保函;

本行作为担保人在此向你放确认承担支付人民币_______________元(大写______________)的责任,在你放书面提出要求得到上述金额内的任何付款时,本行即予支付,不提任何异议,也不要求你方出具证明或说明背景或理由

本行放弃你方应先向乙方要求赔偿上述金额,然后再向本行提出要求的权利。

贵方可按本保函条款向本银行发出一次或多次付款要求,但总金额不得超过保证上限。

我行还同意:在你方和乙方之间的合同条件、合同项下的工程或合同文件发生变化、补充或修改后,我行承担本担保的责任也不改变;上述变化、补充或修改也无须通知我行。

本保函至合同项下全部项目竣工验收合格并移交你方之日内一直有效。

担保人签字盖章:

地 址:

银 行 名 称:

日 期: 年 月 日

相关知识

工程保函是依据商务合同开出的,但又不依附于商务合同,是具有独立法律效力的法律文件。当受益人在保函项下合理索赔时,担保人就必须承担付款责任,而不论申请人是否同意付款,也不管合同履行的实际事实,即保函是独立的承诺并且基本上是单证化的交易业务。

信贷证明信贷证明的背景:当一个工程公开招标,有意向的投标人递交资料准备投标,有时,甲方处于各种原因的考虑,要进行资格预审,只有通过资格预审的施工单位才能进行投标;甲方进行资格预审时,会要求意向投标人提供很多资料,信贷证明就常常要求的一项资料。

履约保函由担保人为施工方(申请人)向业主(受益人)提供的,保证施工方履行工程建设合同责任和义务,承包商不履行合同的,业主可要求保证人在保函金额内承担保证责任。保证人在承担保证责任后,可依法向承包商追偿。保证担保公司提供的履约保函一般为有条件的保函,即在业主提出索赔时必须提供承包商违约的证明,保证人核实后才承担保证责任。履约保证担保也可以适用于分包合同、材料设备供货合同的履行。

质量保修保函质量保修担保是保证人为开发商(申请人)在保修期内按《购买合同》、《质量保证书》的约定履行保修义务,而向购主(权益人)提供的担保。若非购主或不可抗力的原因,开发商没有按照上述文件的约定履行保修义务的,购主有权要求保证人代为履行合同义务或赔偿损失。

预付款保函预付款保证担保是指由保证人为施工方向业主提供的,保证人对施工方履行扣还预付款义务的保证。以防止施工方在收到业主的预付款后将款项挪作他用或宣布破产等。当施工方在规定的时间内还清预付款项后,业主就需退还预付款保函。

履约分包保函当工程存在总包分包关系时,总承包商要为各分包商的工作承担连带责任。总承包商为了保护自身的权益不受损害,往往要求分包商通过担保人为其提供担保,以防止分包商违约或负债。

支付保函(含民工支付担保)业主支付担保是指为保证业主履行工程合同约定的工程款支付义务,由担保人为业主向承包商提供的,保证业主支付工程款的担保。业主在签订工程建设合同的同时,应当向承包商提交业主工程款支付担保。未提交业主工程款支付担保的建设工程,视作建设资金未落实。

履约保证证明应劳务方或投标人(申请人)的请求和业主的要求,担保人向工程的业主方(受益人)所做出的一种履约保证。倘若投标人(申请人)一旦中标,担保人有能力为中标人继续向业主提供合同履约保证,否则担保人向受益人承担赔偿责任。

篇4:银行保函

银行保函

银行保函又称银行保证书,也属银行信用,是指银行应申请人或委托人的要求向受益方开出的,担保申请人一定履行某种义务,并在申请人未能按规定履行其责任和义务时,由担保行代其支付一定金额、或作出一定经济赔偿的书面文件。

分类

根据保函与基础交易合同的关系

⑴从属性保函(Letter of Accessory Guarantee)

⑵独立性保函(Letter of Independence Guarantee)

根据保函索赔条件的不同

⑴无条件保函(Unconditional L/G)

⑵有条件保函(Conditional L/G)

根据保函的使用范围不同

⑴进口类保函

⑵出口类保函

履约保函

在一般货物进出口交易中,履约保函又可分为进口履约保函和出口履约保函。

⒈进口履约保函。

进口履约保函是指担保人应申请人(进口人)的申请开给受益人(出口人)的保证承诺。保函规定,如出口人按期交货后,进口人未按合同规定付款,则由担保人负责偿还。这种履约保函对出口人来说,是一种简便、及时和确定的保障。

⒉出口履约保函

出口履约保函是指担保人应申请人(出口人)的申请开给受益人(进口人)的保证承诺。保函规定,如出口人未能按合同规定交货,担保人负责赔偿进口人的损失。这种履约保函对进口人有一定的保障。

还款保函

还款保函又称预付款保函或定金保函。是指担保人应合同一方当事人的申请,向合同另一方当事人开立的保函。保函规定,如申请人不履行他与受益人订立合同的义务,不将受益人预付或支付的款项退还或还款给受益人,担保人向受益人退还或支付款项。

除上述两种保函外,还可根据其他功能和用途的不同,分为其他种类的保函,如:投标保函、补偿贸易保函、来料加工保函、技术引进保函、维修保函、融资租赁保函、借款保函等等。

(ATA单证册担保函)银行保函范本

担保人名称:

地址:

邮编:

被担保人名称

地址:

邮编:

受益人名称:中国国际商会

地址:xx市复兴门外大街1号

邮编:xxxxxxxxxxx

中国国际商会:

鉴于你会根据xxx年在布鲁塞尔通过的《关于货物暂准进口的ATA单证册海关公约》,或xxx年在伊斯坦布尔通过的'《货物暂准进口公约》,向被担保人签发号码为 的ATA单证册。

应被担保人的申请,我行保证,如你会因这一单证册而支付任何海关关税和/或其他费用,我行在收到你会的书面索付请求后,将在十个工作日内无条件全额赔付你会所支付的款项。我行因本保函而承担的最高担保金额为 元人民币。本保函自签发之日起生效,有效期为33个日历月。

保函终止方式:

1.有效期届满。

2.银行收到受益人解除担保的通知。

3.银行支付了最高金额的担保金。

签字:____________________

_____年_____月____日

盖章:

篇5:银行保函

致:

鉴于_________________________________________(以下简称乙方)已保证按_____________________________(编号:_________________________)(以下称“合同”)实施;

且鉴于你方在上述合同中要求乙方通过经认可的银行向你方提交合同规定金额的不可撤销的银行保函,作为乙方履行合同责任的担保;

而且本行同意为乙方出具本银行保函;

本行作为担保人在此向你放确认承担支付人民币_______________元(大写______________)的责任,在你放书面提出要求得到上述金额内的任何付款时,本行即予支付,不提任何异议,也不要求你方出具证明或说明背景或理由

本行放弃你方应先向乙方要求赔偿上述金额,然后再向本行提出要求的权利。

贵方可按本保函条款向本银行发出一次或多次付款要求,但总金额不得超过保证上限。

我行还同意:在你方和乙方之间的合同条件、合同项下的工程或合同文件发生变化、补充或修改后,我行承担本担保的责任也不改变;上述变化、补充或修改也无须通知我行。

本保函至合同项下全部项目竣工验收合格并移交你方之日内一直有效。

担保人签字盖章:

地 址:

银 行 名 称:

日 期: 年 月 日

相关知识

工程保函是依据商务合同开出的,但又不依附于商务合同,是具有独立法律效力的法律文件。当受益人在保函项下合理索赔时,担保人就必须承担付款责任,而不论申请人是否同意付款,也不管合同履行的实际事实,即保函是独立的承诺并且基本上是单证化的交易业务。

信贷证明信贷证明的背景:当一个工程公开招标,有意向的投标人递交资料准备投标,有时,甲方处于各种原因的考虑,要进行资格预审,只有通过资格预审的施工单位才能进行投标;甲方进行资格预审时,会要求意向投标人提供很多资料,信贷证明就常常要求的一项资料。

履约保函由担保人为施工方(申请人)向业主(受益人)提供的,保证施工方履行工程建设合同责任和义务,承包商不履行合同的,业主可要求保证人在保函金额内承担保证责任。保证人在承担保证责任后,可依法向承包商追偿。保证担保公司提供的履约保函一般为有条件的保函,即在业主提出索赔时必须提供承包商违约的证明,保证人核实后才承担保证责任。履约保证担保也可以适用于分包合同、材料设备供货合同的履行。

质量保修保函质量保修担保是保证人为开发商(申请人)在保修期内按《购买合同》、《质量保证书》的约定履行保修义务,而向购主(权益人)提供的担保。若非购主或不可抗力的原因,开发商没有按照上述文件的约定履行保修义务的,购主有权要求保证人代为履行合同义务或赔偿损失。

预付款保函预付款保证担保是指由保证人为施工方向业主提供的,保证人对施工方履行扣还预付款义务的保证。以防止施工方在收到业主的预付款后将款项挪作他用或宣布破产等。当施工方在规定的时间内还清预付款项后,业主就需退还预付款保函。

履约分包保函当工程存在总包分包关系时,总承包商要为各分包商的工作承担连带责任。总承包商为了保护自身的权益不受损害,往往要求分包商通过担保人为其提供担保,以防止分包商违约或负债。

支付保函(含民工支付担保)业主支付担保是指为保证业主履行工程合同约定的工程款支付义务,由担保人为业主向承包商提供的,保证业主支付工程款的担保。业主在签订工程建设合同的同时,应当向承包商提交业主工程款支付担保。未提交业主工程款支付担保的建设工程,视作建设资金未落实。

履约保证证明应劳务方或投标人(申请人)的请求和业主的要求,担保人向工程的业主方(受益人)所做出的一种履约保证。倘若投标人(申请人)一旦中标,担保人有能力为中标人继续向业主提供合同履约保证,否则担保人向受益人承担赔偿责任。

篇6:银行保函

致:受益人To: The beneficiary 保函编号 Our Ref. No.

出具日期 Date:

经——通知 ADVISED THROUGH_____

敬启者Dear Sirs,

我行第×××号不可撤消保函

Our Irrevocable Letter of Guarantee No.

根据贵方于×年×月×日与××(以下简称甲方)在×××地签署的第××号贷款协议,应甲方的要求,我们特此开立以贵方为受益人的第××号,金额不超过×××的不可撤消担保函。

With reference to the Loan Agreement No. _____ signed between your good selves and______ (hereinafter referred to as Party A) in place on date and at the request of Party A, we hereby establish in your favor an Irrevocable Letter of Guarantee No.______ for an amount not exceeding______ (in words).

我们保证,在贵方向甲方提供了协议所规定的贷款后,甲方将在协议规定的期限内偿还贵方上述贷款及其按年利率百分之×计算的利息。如果甲方未能在协议规定的时间内全部地或部分地偿还有关贷款的本息,我们保证在本保函有效期内收到本保函的通知银行转来的经甲方证实了的`书面索赔通知后,将甲方未偿还之贷款本息偿还给贵方。

We guarantee that, after you provide Party A with the loan as stipulated in the Agreement, they will repay you the principal as well as the interest accrued thereon at______ % p.a. within the time in accordance. with the terms and conditions of the Agreement. Should Party A fail to repay you the loaned amount plus interest wholly or partially within the time limit, we undertake to effect the aforesaid repayment plus interest on their behalf, after we have received from the advising bank within the validity of this L/G your written demand to be verified by Party A.

本保函的担保金额将随甲方或我方已向贵方偿还的本息金额而同比例递减。

The ensured amount under this L/G will reduce in proportion to the amount(s) plus interest already repaid by Party A and/or by us.

本保函自甲方收到贵方的贷款之日起生效,于×年×月×日失效。到期后,请将本保函退还我行注销。

This L/G is valid from the date when Party A receives the said Loan from you until __ and should be returned to us for cancellation upon its expiry.

Guarantor:______

担保人(签字、盖章)

篇7:银行保函

PERFORMANCE BOND

致:受益人

To: The beneficiary 保函编号 Our Ref. No.

出具日期:Date:

敬启者Dear Sirs,

履约保函

PERFORMANCE BOND

本保函是为(申请人名称)(以下简称供货人)根据(合同编号及签署日期)向(受益人)提供(货物名称)而出具的。

This bond is hereby issued to serve as a performance bond of name of the applicant for the supply of name of goods for name of the sales contract and its number.

(担保人名称)特此不可撤消地保证自己、其继承人和受让人在下列情况下,无追索地用美元向你方支付合同金额的×%,即(担保金额):

The name of the guarantor hereby irrevocably guarantees and binds itself, its successors and assignees to pay you, without recourse, up to the total amount of currency and figures representing X percent (X%) of the contract price in US dollar and accordingly covenants and agrees as follows:

(1)如果供货人未能按合同及其后可能作出的合同变更、合同修改、合同补充和合同变动,包括对不合格商品的更换或修补条款履行责任(以下简称违约),则我们在收到你方指出供货人违约的书面通知时,向你方支付索赔书上所要求的一笔或数笔款项,但不超过本保函担保的总金额(担保金额)。

a) On the supplier's failure of the faithful performance of all the contract documents and modifications, amendments, additions and alterations thereof that may hereafter be made, including replacement and/or making good of defective goods (hereinafter called the failure of performance) as determined by you and notwithstanding any objection by the Supplier, the Bank shall, on your demand in a written notification stating the effect of the failure of performance by the Supplier, pay you such amount or amounts as required by you not exceeding in aggregate amount of guarantee in the manner specified in the said statement.

(2)本保函项下的付款将不减去任何现在的或将来的税款、费用扣留等。

b) Any payment hereunder shall be made free and clear of and without deduction for or on account of any present or future taxes, duties, charges, fees, deductions or withholding of any nature whatsoever imposed.

(3)本保函内所含的各项约定构成了担保银行不可撤消的直接责任。上述合同中的任何条款变更,你方所允许的时限或作出的任何行为或发生的疏漏,尽管可能免责或解脱银行,都不能解除银行的此项责任。

c) The covenants contained herein constitute irrevocable direct obligations of the Bank. No alteration in the terms of the contract to be performed there under and no allowance of time by you or any other act or omission by you which for this provision might exonerate or discharge the Bank shall in any way release the Bank from any liability hereunder.

(4)本保函自上述合同签署之日起生效直至(合同失效日)为止。本保函到期后,请将其退回我方注销。

d) This guarantee shall become effective from that date of the signing of the said contract and shall remain valid until the date of its expiry. Upon expiry, please return this guarantee to us for cancellation.

担保人:(签字、盖章)

Guarantor:______

篇8:银行保函

致:受益人To:The beneficiary 保函编号:Our Ref.No

出具日期:Date:

敬启者:Dear Sirs,

我行第××号预付货款保函

Our Advance Payment Guarantee No....

鉴于贵方根据与(申请人名称)(以下简称合同方)于×年×月×日签署的第××号合同的有关条款的规定,在收到合同方提供的有关预付货款保函后,将向合同方预付(预付金额)作为合同项下的预付款。

WHEREAS according t0 the terms and conditions of the sales contract No…signed between you and name of the Applicant (hereinafter referred to as the Contractor) ,you shall.on receipt from the Contractor of a bank guarantee for such advance payment to you· make an advance payment of—amount in figures and in words to the Contractor as an advance payment thereunder.

我们(担保人名称)应合同方的要求,特此开立本保函并向你方不可撤消地保证,在收到你方书面索赔通知声明合同方未能履行上述合同有关条款时,支付给你方不超过担保金额的款项。

NOW THEREFORE,we(name of guarantor)at the request of the Contractor hereby irrevocably issue this Advance Payment Guarantee and undertake to pay you, upon receipt of your written demand stating that the Contractor has failed to perform his obligations as stipulated in the Contract, the sum or sums not exceeding the above-mentioned amount.

我们在本保函项下的担保责任仅限于(保函金额)。

Our liability hereunder shall be limited to (the amount of guarantee).

本保函从合同方收到你方支付的上述预付款之日起生效,到(保函失效日)失效。 我们的担保责任将随合同方已经支付给你方的金额而自动同比递减。 保函到期后,请退回我们注销。

This guarantee shall become effective on the date the Contractor receives the aforesaid advance payment from you and shall remain valid until (the expiry date of this guarantee). The guaranteed amount shall be automatically and proportionally reduced by the amount which the Contractor has already repaid to you. Upon its expiry, please return this guarantee to us for cancellation.

担保人:(签字、盖章)

Guarantor: (signature, seal)

篇9:七份银行保函

APPLICATION FOR GUARANTEE (BID BOND)

Undertaking to fulfil the terms and conditions of the' AGREEMENT submitted to you, we hereby request you to issue a Letter of Guarantee as bid bond in accordance with the column marked (X) shown below.

我们在保证执行所递交协议的条款和条件时,特此要求你们按照下面所选项目出具一份保函作为投标保证。

( ) Please issue and advise the beneficiary of your issuing the following Letter of Guarantee reading:

( )请出具下述内容的保函并通知受益人:

篇10:七份银行保函

Letter of Guarantee (Bid Bond)

At the request of and for account of. .. We hereby issue this irrevocable Letter of Guarantee amounting to USD...in favor of XYZ Company as Bid Bond for the tender opening on (date) called by the beneficiary under the tender No

应(申请人名称)的要求并作为其代理,我们特此出具以( )为受益人、金额为( )不可撤销的本保函,作为受益人根据( )开标的第( )标书所要求的投标保证书。

We, ABC Bank, hereby guarantee to pay the above-mentioned amount under this Letter of Guarantee subject to the following conditions:

我们( )银行特此保证支付本保函项下的上述金额,只要符合以下条件:

The above-mentioned amount be paid to the beneficiary through your fine bank in case the accountee does not enter into contract with the beneficiary for the reasons to be solely attributed to the accountee despite his /her success in the aforesaid bid and consequently corresponding bid bond should be confiscated by the beneficiary.

申请人(即投标人)尽管中标,但完全出于其自身的多种原因不与受益人签定合同,结果相应的投标保证书只好被受益人收回,在这种情况下,上述金额应当通过你们的银行支付给受益人。

This Guarantee remains in force until (date), after which this Guarantee becomes null and void automatically and should be returned to us.

本保函的有效期继续到( )为止,过了这一天本保函便自动失去效力并应当退还给我们。

This Guarantee shall be released in full immediately when the accountee fails the bid.

申请人放弃投标时本保函应立即完全解除。

( ) Please issue a Letter of Guarantee as per form attached hereto, terms and conditions of which remain unchanged as per our written agreement dated...

( )请按照本申请书所附格式出具一份保函,因为根据我们于( )日所定的书面协议内的条款和条件没有改变。

( ) Please have anyone of your correspondent banks issue its own guarantee in accordance with the terms and conditions of the attached form.

( )请委托你们的任何一家代理银行按照所附格式内的条款和条件出具其自己的保函。

注释:

1.BID BOND投标保证金,押标保证,押标保证金。本文指投标契约,即投标保证书。

2.In favor of,(f/o)以某某为受益人。金融业务中使用频繁,f/o可译作“受益人”。类似的缩写如c/o由某人转交,AD,a/d (after date)出票日后,发票后,期后,AS,a/s(after sight)见票后。

3.Subject to,这里Subject是副词,须和to连用,意为“在……条件下”,或者译为“条件是”等,本文译作“只要符合……条件”,比较恰当。

4.Accountee原意指开证(信用证)申请人,被记帐人(汇兑)。这里指前面的申请人(applicant)。

5.Be attributed to把……归因于,把……归咎于。根据上下文,这里译作“出于……原因”。比较:Be attributable to,可以归因于……前者语气肯定,后者不肯定,使用时,应注意二者的区别。Fail不及物、及物动词。本文为及物动词,指舍弃,放弃。

篇11:七份银行保函

致:To:

不可撤消保函 号码

Irrevocable Letter of Guarantee No.

鉴于你方向借款人提供了一笔贷款,我行特此为借款人出具本保函并保证如下:

In consideration of your making a loan available to the Borrower _____ we hereby issue this guarantee for the account of the Borrower and agree as follows:

1.我行在此无条件地不可撤消地保证,借款人在贷款到期或发生加速还款或其他情况下,按时偿还贷款协议(包括经我行书面同意的对该协议的修改和补充)项下现时或将来的到期款项。保证金额最高不超过_____ 美元(即贷款本金加利息的110%)。如果借款人到期不能归还该等款项,我行将凭你方书面索赔立即偿还。除非有明显的错误,由你方授权官员签发的载明该等应还款细节及到期日的任何声明应是终局的并对我行具有约束力。

1. We hereby unconditionally and irrevocably guarantee to make repayment on time (the due and punctual payment—1) up to the amount of USD_____ (110% of the principal plus accrued interest) which is or may become repayable ( payable —2 ) by the Borrower under the Loan Agreement between the Lender and the Borrower which shall include all subsequent amendments and supplements made to the Loan Agreement (the Loan Agreement as amended or supplemented from time to time —3) with our consent in writing, whether at maturity or upon acceleration or otherwise. If the Borrower fails to repay (pay —4) any such sum when due, we shall pay you the amount on the date of our receipt of your claim in writing. Any statement signed by your duly authorized officer that gives (setting out —5) details and the due date of any such claim shall be conclusive and binding on us except in the case of manifest error.

2.本保函自开立之日起生效,直至_____ (贷款协议到期后6个月)失效。随着贷款协议项下本金的每一期偿还,我行的担保责任亦应相应递减。我行在本保函项下的担保责任将不受下列事件的影响:对借款人给予延期还款等优惠;或贷款人不行使对借款人享有的权利;或由于本款规定可能影响我行在本保函项下责任的其他原因或情况,但前提是对该贷款协议的任何修改或补充须经我行事前书面确认,我行亦保证不会不合理地耽搁或拖延此种确认。对本保函项下的索赔可随时进行,贷款人在向我行索赔前,无须采取任何措施以实现其对借款人或其继承人的权利。

2. This Guarantee shall become ( be —6 ) effective on the date hereof and shall expire on_____ (six months after the expiry due—7) date of the Loan Agreement. Following each repayment of principal under the Loan Agreement, our liability hereunder shall be reduced accordingly. Our liability hereunder shall not be affected by the granting of any indulgence to the Borrower, or by any defect in the rights of the Lender against the Borrower, or by any other matter or circumstance which, due to this provision, may affect our liability hereunder, provided that any amendments or supplements to (of—8 ) the Loan Agreement are subject to our prior written approval which we undertake we will not (undertake not to—9 )unreasonably withhold (withhold —10) or delay(delay —10 ). The Lender may hereupon lodge demands upon us from time to time and would not be required to take any step to exercise his rights against the Borrower before claiming upon us.

3.本保函项下索赔款的支付不得包括任何抵消、反索赔、限制以及豁免于任何现有或将来的税收或其他扣减或任何性质的预留。如果在索赔款的支付中必须包含任何扣减或预留,我行除索赔款金额外,还将支付该等必要的附加费用,从而确保贷款人得到应收回的足额还款。

3.A1l payments under this Guarantee shall be made without any setoff or counterclaim or(any—11) restriction or exempt from(condition and free of —12 any present or future taxes or other deductions or withholdings of any nature. If any deduction or withholding must be included in the payment of the claim(is required to be made from any such payment—13) we shall (together with payment—14) of the claim)pay such additional amount together with payment of the claim(such payment—15)as is necessary to ensure the Lender's receipt of(the Lender receive—16)the full amount due to him(them—17).

4.我行在此确认已获得对本保函或与本保函有关的所有法人同意,认可以及相应政府部门或其他有关当局的批准,该等批准是充分有效的。本保函的条款构成我行合法、有效并具有约束力的责任,我行在本保函项下的责任将在任何时刻至少与我行其他未担保以及非从属债务处于同等地位,我行保证为此目的的全部必要授权一直是充分的、有效的。

4.We hereby represent and undertake that all corporate consents and approval, and approval from the governmental or any other authorities involved in this Guarantee have been obtained and are in full force and effect.This Guarantee constitutes our legal.valid and binding obligations enforceable in accordance with its terms,and our obligations hereunder will at all times rank at least pari-passu with all of our other unsecured and insubordinate(unsubordinated—18)obligations.We confirm(will ensure—19)that all authorizations necessary for this purpose remain in full force and effect.

5.贷款人在本保函项下疏于或怠于行使任何权利或补救措施等,均不应视为对该等权利的放弃;任何单项或部分行使上述权利也不能排除贷款人进一步采取行动或行使其他权利或补救措施的权利。如果在任何时候本保函的任何条款已是或变为非法、无效或在任何方面不可执行,本保函其他条款的合法性、有效性及可执行性均不应受到影响或相应降低。

5.No failure or delay by the Lender in exercising any right。power or remedy under this Guarantee shall operate as waiver thereof,nor shall any single or partial exercise of the same preclude any further exercise thereof or the exercise of any other right,power or remedy.If at any time any provision in this guarantee (hereof—20)is or becomes illegal,invalid or unenforceable in any respect, neither the legality,validity or enforceability of the remaining provisions herein shall in any way be affected or impaired thereby.

6.我行将偿付贷款人因行使其在本保函项下权利而发生的全部合理费用(包括律师费用)。

6.We shall reimburse the Lender for all reasonable(fees and—21) expenses (including lawyer's fee)incurred in connection with the enforcement of his rights hereunder.

7.我行将对本保函项下的任何迟付金额按借款人应用的利率水平支付利息,该付息期间的计算从你方索偿之日起,直至实际付款日止(在判决前或判决后)。

7.We shall pay interest on any amount due hereunder from the date of demand to the date of actual payment (before and after judgement)at the rate 0r rates which should be applied(would be payable—23)by the Borrower.

8.未经我行事前书面同意,本保函项下的权益不可以转让,我行亦确认不会不合理地拖延该等同意。

8.The benefit of this Guarantee may not be assigned without our prior written consent,such consent not to be unreasonably withheld.

9.本保函应确保贷款人和其相应后继者的权益。不论我行或我行相应后继者的组织和机构有任何变化,在保函项下的义务对我行及我行后继者持续具有约束力。在不违反上述第8条的情况下,贷款人可以将其在本保函项下或由于本保函、贷款协议及其他担保契约(根据贷款协议的定义)而派生的权利或权益全部或部分地转让给任何他人。

9.This Guarantee shall assure(ensure to the benefit of—24)the Lender and his(their—25)successor/S of his/their rights and interests(its—26).Our obligations hereunder shall be binding on us and our successor/s notwithstanding any change in our constitution or status or that of Our successor/S.Subject t0 Article 8 above, the Lender may assign to any other person all or any part of his (its—27 ) rights and benefits under or arising from this Guarantee, the Loan Agreement and any other security documents (as defined in the Loan Agreement) ( subject to Article 8above—28 ).

10.我行在此确认本保函的签定和执行是一种商业行为,并同意放弃采取与本保函有关的任何法律行为或程序的豁免权。

10. We confirm that the signing and execution (and performance—29) of this Guarantee are a commercial act and agree not to claim any immunity from any legal action or proceeding in connection herewith.

11.本保函受中华人民共和国法律管辖并按其法律解释,我行将不可撤消地接受中华人民共和国法院的司法管辖。

11. This Guarantee shall be governed by and construed in accordance with the laws of the People's Republic of China, and we hereby irrevocably submit to the jurisdiction of the courts in the country.

日期:Issued in (city) on (date)

以______ 的名义并代表其签字

(授权签字)

For and on behalf of

(authorized signature )

相关专题 类型银行